Господарські та будівельні товари
Valid:
Oct 23, 2020 – Dec 31, 2020
Contract ID :
UA-2020-10-27-001603-b-a1
Number:
№36
Date of signature:
Oct 23, 2020, 00:00
Items list
| Name | Quantity | Delivery period | Place of delivery |
|---|---|---|---|
|
Name: Господарські та будівельні товари
Code DK 021:2015:
44111000-1 Будівельні матеріали
|
Quantity: 115 найменувань |
Delivery period: Nov 6, 2020, 16:00 |
Place of delivery: Україна, 23400, Вінницька область, смт.Муровані Курилівці, вул. Спортивна 3 |
Changes to contract
Change №1
Status:
Confirmed
Change cause:
Improvement of the quality of the subject of procurement provided that such improvement will not lead to an increase in the amount specified in the contract
Note:
Збільшення постачання господарських та будівельних товарів
ID:
5b4275071d5842f089e40fbfbf279e4f
Date:
Dec 14, 2020, 10:01
Number of loaded document:
№2
Date of signature:
Dec 9, 2020, 00:00
| Document name | Document type | Date of publishing |
| Annexes to the contract | Dec 14, 2020, 10:01 |
Change №2
Status:
Confirmed
Change cause:
Change of price per unit of goods by no more than 10% in case of price fluctuation of such goods on the market, provided that such change does not lead to an increase in the amount specified in the contract
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Note:
Додаткове збільшення постачання господарських та будівельних товарів
ID:
0802067333a94d19a2d2c224c2874acb
Date:
Dec 23, 2020, 12:15
Number of loaded document:
№3
Date of signature:
Dec 18, 2020, 00:00
| Document name | Document type | Date of publishing |
| Annexes to the contract | Dec 23, 2020, 12:14 |
Main contact
Name:
Кравчук Олександр Васильович
Phone:
+380435621055
E-mail:
Fax:
+380435621188
Information about supplier
Name:
ФОП Фірманюк Антон Володимирович
EDRPOU code:
3412000974
Website:
Not indicated
Address:
Україна, 23400, Вінницька область, смт.Муровані Курилівці, вул. Чапаєва,43
Information about customer
Name:
Мурованокуриловецька загальноосвітня санаторна школа-інтернат І-ІІІ ступенів Вінницької обласної Ради
EDRPOU code:
20085915
Website:
Not indicated
Address:
Україна, 23400, Вінницька область, смт Муровані Курилівці, вул Спортивна 3