Здійснення технічного нагляду під час будівництва об’єкта: «Реконструкція території благоустрою майдану Мистецькі Ворота в м. Житомирі» (CPV ДК 021:2015 71520000-9 Послуги з нагляду за виконанням будівельних робіт)
Valid:
Nov 3, 2021 – Dec 31, 2023
Contract ID :
UA-2021-09-28-010484-b-c1
Number:
97
Date of signature:
Nov 3, 2021, 11:11
Items list
| Name | Quantity | Delivery period | Place of delivery |
|---|---|---|---|
|
Name: Здійснення технічного нагляду під час будівництва об’єкта: «Реконструкція території благоустрою майдану Мистецькі Ворота в м. Житомирі» (CPV ДК 021:2015 71520000-9 Послуги з нагляду за виконанням будівельних робіт)
Code DK 021:2015:
71520000-9 Послуги з нагляду за виконанням будівельних робіт
|
Quantity: 1 роботи |
Delivery period: Oct 20, 2021, 00:00 – Dec 31, 2022, 00:00 |
Place of delivery: Україна, 10001, Житомирська область, Житомир, майдан Мистецькі Ворота |
Procurement documents
| Document name | Document type | Date of publishing |
| Not indicated | Nov 7, 2023, 16:49 | |
| Not indicated | Nov 4, 2021, 11:12 | |
|
|
||
| Signed contract | Nov 4, 2021, 11:11 | |
Changes to contract
Change №1
Status:
Confirmed
Change cause:
Extension of the contract and the fulfillment of obligations under transfer of the goods, works performance, rendering of services in the case of a documented objective circumstances that led to such extension, including force majeure, delays in financing customer expenses, provided that such changes will not increase contract budget.
Note:
Нова редакція п. 2.1. договору
ID:
e7d3ba65c4824339b3d180e7d89b9134
Date:
Dec 23, 2021, 14:17
Number of loaded document:
1
Date of signature:
Dec 22, 2021, 14:17
| Document name | Document type | Date of publishing |
| Not indicated | Dec 23, 2021, 14:17 | |
| Annexes to the contract | Dec 23, 2021, 14:17 |
Change №2
Status:
Confirmed
Change cause:
Improving the quality of procurement subject, provided that such improvement will not increase contract budget
Note:
Нова редакція п. 2.1. договору
ID:
5aa24d75232c4d61b1994e74653633c2
Date:
Mar 24, 2022, 12:30
Number of loaded document:
2
Date of signature:
Mar 24, 2022, 12:29
| Document name | Document type | Date of publishing |
| Not indicated | Mar 24, 2022, 12:30 | |
| Annexes to the contract | Mar 24, 2022, 12:29 |
Change №3
Status:
Confirmed
Change cause:
Extension of the contract and the fulfillment of obligations under transfer of the goods, works performance, rendering of services in the case of a documented objective circumstances that led to such extension, including force majeure, delays in financing customer expenses, provided that such changes will not increase contract budget.
Note:
Нова редакція п. 1.2. договору
ID:
2c7d67017ae741ecb1b29d849f6c2ab1
Date:
Apr 21, 2022, 16:27
Number of loaded document:
3
Date of signature:
Apr 21, 2022, 16:26
| Document name | Document type | Date of publishing |
| Not indicated | Apr 21, 2022, 16:27 | |
| Annexes to the contract | Apr 21, 2022, 16:26 |
Change №4
Status:
Confirmed
Change cause:
Extension of the contract and the fulfillment of obligations under transfer of the goods, works performance, rendering of services in the case of a documented objective circumstances that led to such extension, including force majeure, delays in financing customer expenses, provided that such changes will not increase contract budget.
Note:
Прийняття в новій редакції п. 1.2. договору у зв'язку із продовженням виконанння будівельних робіт
ID:
5751a118b6074c888b472159441f317c
Date:
Dec 7, 2022, 12:47
Number of loaded document:
4
Date of signature:
Dec 6, 2022, 10:16
| Document name | Document type | Date of publishing |
| Not indicated | Dec 7, 2022, 12:47 | |
| Annexes to the contract | Dec 7, 2022, 10:18 |
Change №5
Status:
Confirmed
Change cause:
Extension of the contract and the fulfillment of obligations under transfer of the goods, works performance, rendering of services in the case of a documented objective circumstances that led to such extension, including force majeure, delays in financing customer expenses, provided that such changes will not increase contract budget.
Note:
Прийняття в новій редакції п. 2.1, 10.1. договору
ID:
7a9ae0e3878f4043949cd865c6ccf641
Date:
Dec 26, 2022, 15:35
Number of loaded document:
5
Date of signature:
Dec 26, 2022, 15:32
| Document name | Document type | Date of publishing |
| Not indicated | Dec 26, 2022, 15:35 | |
| Annexes to the contract | Dec 26, 2022, 15:33 |
Change №6
Status:
Confirmed
Change cause:
Improving the quality of procurement subject, provided that such improvement will not increase contract budget
Note:
Прийняття в новій редакції п. 2.1 договору у зв'язку з виділенням фінансування.
ID:
8b2d8ce494cc45d9b7945032f4c19ea5
Date:
Mar 21, 2023, 08:33
Number of loaded document:
6
Date of signature:
Mar 20, 2023, 08:28
| Document name | Document type | Date of publishing |
| Not indicated | Mar 21, 2023, 08:33 | |
| Annexes to the contract | Mar 21, 2023, 08:31 |
Change №7
Status:
Confirmed
Change cause:
The agreed price change towards reduction (without changing the amount (volume) and quality of goods, works and services)
Note:
Прийняття в новій редакції п. 2.1. Договору
ID:
a66bc763139d43b999815e82809299ec
Date:
Nov 7, 2023, 14:45
Number of loaded document:
7
Date of signature:
Nov 7, 2023, 16:29
| Document name | Document type | Date of publishing |
| Not indicated | Nov 7, 2023, 16:45 | |
| Annexes to the contract | Nov 7, 2023, 16:40 |
Main contact
Name:
В'ячеслав Глазунов
Phone:
+380412445716
E-mail:
ukbgmr@i.ua
Fax:
—
Information about supplier
Name:
ФОП Парфенюк Дмитро Юрійович
EDRPOU code:
2294303257
Web site:
Not indicated
Address:
Україна, 10031, Житомирська область, Житомир, вул.Крошенська, буд.№4, кв.41
Information about customer
Name:
Управління капітального будівництва Житомирської міської ради
EDRPOU code:
36072499
Web site:
Not indicated
Address:
Україна, 10014, Житомирська область, м.Житомир, МАЙДАН ІМ. С.П.КОРОЛЬОВА, 4/2