Капітальний ремонт освітлення вул. 24 Серпня в м. Івано-Франківську (ДК 021:2015 - 45316000-5 - Монтаж систем освітлення і сигналізації)
Valid:
Aug 19, 2021 – Dec 31, 2023
Contract ID :
UA-2021-08-05-013771-a-a1
Number:
220/21
Date of signature:
Aug 19, 2021, 14:04
Items list
| Name | Quantity | Delivery period | Place of delivery |
|---|---|---|---|
|
Name: Капітальний ремонт освітлення вул. 24 Серпня в м. Івано-Франківську (ДК 021:2015 - 45316000-5 - Монтаж систем освітлення і сигналізації)
Code DK 021:2015:
45316000-5 Монтаж систем освітлення і сигналізації
|
Quantity: 1 роботи |
Delivery period: Dec 31, 2023, 00:00 |
Place of delivery: Україна, 76000, Івано-Франківська область, м. Івано-Франківськ, вул. 24 Серпня |
Procurement documents
| Document name | Document type | Date of publishing |
| Signed contract | Aug 19, 2021, 15:39 | |
| Annexes to the contract | Dec 15, 2023, 10:46 | |
| Electronic signature | Aug 19, 2021, 15:41 | |
| Electronic signature | Aug 19, 2021, 15:41 | |
|
|
||
Changes to contract
Change №1
Status:
Confirmed
Change cause:
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Note:
у зв'язку із затримкою фінансування витрат Замовника, що підтверджує виникнення об'єктивних обставин, які спричинили продовження виконання зобов'язань по даному Договору, керуючись Цивільним кодексом України, Господарським кодексом України, Законом України "Про публічні закупівлі" зі змінами та доповненнями, умовами Договору підряду, Сторони погодили внести зміни до Договору підряду.
ID:
e5dfcd7fb8504ec391fd4c4271102644
Date:
Aug 20, 2021, 14:01
Number of loaded document:
224/21
Date of signature:
Aug 20, 2021, 13:58
| Document name | Document type | Date of publishing |
| Annexes to the contract | Aug 20, 2021, 14:00 | |
| Electronic signature | Aug 20, 2021, 14:01 |
Change №2
Status:
Confirmed
Change cause:
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Note:
у зв'язку із затримкою фінансування витрат замовника, що підтверджують виникнення об'єктивних обставин, які спричинили продовження зобов'язань по даному договору, керуючись Цивільним кодексом України, Господарським кодексом України, Законом України "Про публічні закупівлі".
ID:
b756f7f026ba445bb7ffe5be5c804c71
Date:
Sep 23, 2021, 16:28
Number of loaded document:
279-2/21
Date of signature:
Sep 20, 2021, 16:22
| Document name | Document type | Date of publishing |
| Annexes to the contract | Sep 23, 2021, 16:28 | |
| Electronic signature | Sep 23, 2021, 16:28 |
Change №3
Status:
Confirmed
Change cause:
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Note:
У зв'язку із затримкою бюджетного фінансування витрат Замовника та відсутністю бюджетних призначень в повному обсязі у 2021 р., що підтверджує виникнення об'єктивних обставин, які спричинили продовження виконання зобов'язань по даному Договору, керуючись Цивільним кодексом України, Господарським кодексом України, Законом України "Про публічні закупівлі" (зі змінами та доповненнями), умовами даного Договору підряду, сторони погодили внести зміни до Договору підряду.
ID:
6ec42e5a1dbb4a62828517ff5b3fb786
Date:
Dec 31, 2021, 08:59
Number of loaded document:
510/21
Date of signature:
Dec 30, 2021, 08:53
| Document name | Document type | Date of publishing |
| Annexes to the contract | Dec 31, 2021, 08:57 | |
| Electronic signature | Dec 31, 2021, 08:59 |
Change №4
Status:
Confirmed
Change cause:
Extension of the contract term and fulfillment of obligations for transfer of goods, performance of works, provision of services in case of occurrence of documented objectively justified circumstances that caused such extension, including force majeure, delay in financing of customer's expenses, provided that such changes will not lead to an increase in the amount specified in the contract
Note:
У зв'язку із затримкою бюджетного фінансування витрат Замовника, що підтверджує виникнення об'єктивних обставин, які спричинили продовження виконання зобов'язань по даному Договору, керуючись Цивільним кодексом України, Господарським кодексом України, Законом України "Про публічні закупівлі", умовами даного Договору підряду, Сторони погодили внести зміни до Договору підряду.
ID:
343717b56de943c9b833532f045b989d
Date:
Dec 30, 2022, 10:23
Number of loaded document:
353/22
Date of signature:
Dec 30, 2022, 10:19
| Document name | Document type | Date of publishing |
| Electronic signature | Dec 30, 2022, 10:23 | |
| Annexes to the contract | Dec 30, 2022, 10:21 |
Main contact
Information about supplier
Name:
ФОП "ПРИГОДА ВОЛОДИМИР ФЕДОРОВИЧ"
EDRPOU code:
2413011253
Website:
Not indicated
Address:
Україна, 76018, Івано-Франківська область, місто Івано-Франківськ, ВУЛИЦЯ ВОЛИНСЬКА, будинок 5А
Information about customer
Name:
ДЕПАРТАМЕНТ БЛАГОУСТРОЮ ІВАНО-ФРАНКІВСЬКОЇ МІСЬКОЇ РАДИ
EDRPOU code:
43905443
Website:
Not indicated
Address:
Україна, 76018, Івано-Франківська область, м. Івано-Франківськ, вул. Незалежності, 7